The words you are searching are inside this book. To get more targeted content, please make full-text search by clicking here.
Discover the best professional documents and content resources in AnyFlip Document Base.
Search
Published by adverts.structureanddesign, 2021-09-14 02:43:15

IAZ Yearbook 2018 Digital New

IAZ Yearbook 2018 Digital New

ARCHITECTS’

YEARBOOK
2018

ARCHITECTS’ YEARBOOK
2

INSTITUTE OF ARCHITECTS ZIMBABWE
3

ARCHITECTS’ YEARBOOK
4

INSTITUTE OF ARCHITECTS ZIMBABWE

CONTENTS

President’s Introduction 8

Appointing an Architect – A Client’s Guide 9
i. What is an Architect? 9
ii. What does an Architect do? 10
iii. How do you select an Architect? 10
iv. How do you appoint an Architect?

Ensure Your Architect Is The Real Thing 12

Institute of Architects in Zimbabwe 13
i. Description
ii. Composition of Board
iii.Past Presidents

Architects Council 14
i. Description
ii. Past Chairmen

Architecture as a Career 16

Examination in Professional Practice 19

Guidelines for Registration Requirements in Zimbabwe 21

Temporary Registration 22

Procedure for Registering as an Architect and joining the Institute of Architects in Zimbabwe 22

Architects (Conditions of Engagement and Scale of Fees) By-laws, S.I. 289 of 1980 25

Directory of Architects 38

Register For Associate Members 63

5

ARCHITECTS’ YEARBOOK
6

INSTITUTE OF ARCHITECTS ZIMBABWE

7

80 HOMES & STYLES MAGAZINE 3

ARCHITECTS’ YEARBOOK

INTRODUCTION

The Institute of Architects of Zimbabwe has over the years been producing publications whose main objectives were
to inform the local, regional and international society on Architecture in Zimbabwe. It contains the list and brief
profiles of all registered Architects in Zimbabwe, Associate members, affiliate members and retired members.
The 2018 Yearbook has been further expanded and includes detailed information for those interested in
making a career of Architecture. It provides detailed guidance for graduates of architecture on Registration and
Membership of the Institute.
It is important to note that Architects are not permitted to advertise or to compete with each other on fees for
architectural services. This yearbook is an approved magazine that allows Architects to profile in brief some
of their works to enable clients and other professionals to have an appreciation of the diverse Architectural
talent that Zimbabwe boasts. The Yearbook therefore takes an added significance by being the Principal format
through which the Architect can make you aware of his or her existence. The Institute of Architects of Zimbabwe
collaborates with Structure and Design Magazine in the publication of articles on works done by Architects.
The Institute of Architects of Zimbabwe maintains an office in Harare, and should you require any information
whatsoever on architecture, our Architects Secretary will be delighted to assist you.
Emiel Murwira
President, Institute of Architects of Zimbabwe.
Office Address:
The Institute of Architects of Zimbabwe, 3 Dorking House, 115 J. Chinamano, Harare, Zimbabwe
Telephone: +263 242 704 242 — 09:00hrs to 16:00hrs
Email: [email protected]
Website: www.architects.org.zw

8

INSTITUTE OF ARCHITECTS ZIMBABWE

WHAT IS AN ARCHITECT?

An Architect is a trained designer of buildings and building related fields, and has expertise not only as a problem
solver, but in being able to analyse and define problems. In analysing a client’s brief the Architect is able to offer
alternative solutions from which a client may select and can offer the client alternative ways of viewing the same
problem.

The Architect combines creative ability, technical knowledge and managerial expertise to be able to interpret
a client’s requirements into built form. He takes into account the restrictions of site and budget, of statutory
regulations, of culture, climate and geographical setting and is able to produce buildings and environments that
are useful, well designed and pleasing to their owners and users.

The Architect is the natural leader of the building design team. His multi-disciplinary training in the related
fields of building construction, engineering structures and systems, building economics and budgeting, contract
administration and construction law, combined with his managerial and design skills, give the Architect a unique
overview of the building process. He will advise on the appointment of specialist engineers or quantity surveyors
and co-ordinate their various services to meet the building programme.

Architects are employed in Government departments and parastatal bodies, large corporates, in Municipal
and private offices. Principals in the private sector are required to be registered in terms of the Architects Act
(1975). Architects in Government or Local Government service are exempt. An Architect in the private sector in
Zimbabwe is a qualified person legally registered and bound by a professional code of conduct. He competes with
his colleagues on the basis of skill and reputation. He is not allowed to compete on the basis of reduced fees or by
advertising. As the client’s agent he carries important financial and environmental responsibilities.

WHAT DOES AN ARCHITECT DO?

An Architect can tackle any building problem, however large or small whether urban or rural. Some offices may
have preferences for the type of work they handle, but an Architect coming fresh to a new brief is just as likely to
produce a good answer as one who has tackled similar briefs many times.

An Architect may have particular skills in addition to those already described. He may also be a specialist in town
planning and urban design, or in interior design, or landscape design, or renovation of older buildings.

Most building projects proceed in the following manner, with the Architect taking the project through a number of
stages:

1. BRIEF: Discussions with a client, establishing and analysing the client’s requirements.

2. FEASIBILITY STUDIES: Testing alternative proposals, looking at each in terms of value for money
and the options each solution offers the client. Research into local regulations, site limitations and
other constraints. Some projects do not proceed beyond this or the next stage.

3. PROJECT: Drawing outline plans, sections, elevations and maybe perspective sketches or making a
three dimensional model, to communicate the essential characteristics of the proposed building to
a client obtaining his approval and producing final be design.

4. CONTRACT: Preparation of detailed information required for Building By-laws, Town Planning
and other legislative approvals and for construction. Production drawings show how each building
component is constructed and built against another, while schedules and bills of quantities list and
describe all the materials required. Detail design can involve consultation with other specialists,
i.e. quantity surveyors, structural engineers, and suppliers of specialised equipment, as well
as with the client and the Local Authority. The tender stage requires the obtaining of prices from

9

ARCHITECTS’ YEARBOOK

builders, making recommendations to the client, preparing the Contract documents for signature.

5. SUPERVISION: The last but not least important part of an Architect’s work is to see that the
building is built in accordance with the original drawings and specifications, and to assist in solving
any unforeseen problems that may arise on site. The Architect works to the benefit of both the
client and the building contractor, and although employed by the client, must remain impartial in
any dispute which might arise.

In addition to these tasks, the Architect is often called upon to carry out surveys of existing buildings, advise on
defects and maintenance problems as well as to advise on alterations that may be required.

HOW DO YOU SELECT AN ARCHITECT?

A current list of registered Architects and firms is always available from the Institute of Architects of Zimbabwe.

Architectural firms range in size from one-man offices to organisations employing quite a number of assistants
and technicians. Some large offices prefer not to be involved in small projects, while small practices may not be
so experienced in larger projects. Some firms have wide experience and larger manpower resources to draw
upon. Others may have exceptional design ability and an enthusiastic approach to their work. No matter what the
size of the firm, all are controlled by qualified Architects trained to be able to deal with your project.

Firms may be contacted directly to find out whether they are interested in your project. Those that are interested
may then be requested to submit details of relevant experience, with a view to making a shortlist for interview.

Such an interview might ideally take place at the Architect’s office where drawings, photographs and models of
his work are available. Questions which may be asked include:

• what special expertise the firm can offer?
• how busy is the firm and their capacity to satisfy your programme?
• who will be responsible for your project, and an assessment of how well you might be able to
work and communicate together?
• does the firm carry professional indemnity or insurance?

This provides cover against the risk of claims which might be awarded against the Architect, which if awarded
against him, could place him in financial difficulties and consequently jeopardize your project.

When all the Architects under consideration have been seen, you may wish to visit at least one completed building
with each Architect you consider suitable for your project.

With all the information gathered, and having carefully considered all aspects, it must then ultimately be your
own judgement as to which Architect you select.

For major projects, an Architectural competition open to the whole profession or to a number of selected
Architects, is often a particularly appropriate method. The extra time and cost involved is proportionate to the cost
of the building, in return for which the client benefits by having a number of schemes from which to choose. The
Institute of Architects of Zimbabwe lay down regulations for the conduct of different types of competitions and are
able to advise and assist in the administration required.

HOW DO YOU APPOINT AN ARCHITECT?

It is important that the scope of the work to be carried out and the fees to be charged are clearly set down
in writing from the outset. To this end the Institute publishes a standard form of Architects Appointment,
which includes the statutory Conditions and Engagement and Scale of Fees. This document outlines in detail
the general and specific duties of an Architect, the manner in which disputes should be handled, or services

10

INSTITUTE OF ARCHITECTS ZIMBABWE

terminated. It also sets down the minimum fees chargeable.
It is essential in achieving a successful building that client and Architect work together as a team. It is important
that your brief and schedule of accommodation is as complete and well thought out as possible. Strong likes and
dislikes of materials forms or styles should be communicated to the Architect at the beginning of the project.
Bear in mind that he is an expert in translating your requirements into reality and you should allow him to
maximise that expertise, for which you are paying.
Be very frank with your Architect as to the financial constraints on the project and the amount available for the
building. It is then the Architect’s responsibility to design within that budget.

Go very thoroughly into the proposals at the design stage and do not give approval to proceed to the next stage of
work until you are totally satisfied with the proposed scheme.

Once building has begun, try to avoid changes on site. They are much cheaper to make while the scheme is on the
drawing board and can cause significant delays for the completion, as well as giving rise to costly claims being
made by the contractor.

Maintain your interest in the building as it progresses, but never give instructions directly to the builder. Always give
these through the Architect; this is a very common cause of disputes arising on site.

Pay the builder promptly when the Architect certifies that payments are required. Failure to do so could put you
into breach of Contract.

Do not hesitate to discuss any worries you may have with your Architect. He relies on your confidence and trust,
as much as you rely on his skills and commitment to your project.

11

ARCHITECTS’ YEARBOOK

ENSURE THAT YOUR ARCHITECT
IS THE REAL THING

Unfortunately there are unqualified people out there who are masquerading as Architects - so its worth asking
your Architect to confirm their legitimacy as a Registered Architect - if they are the real thing they’ll have no issue
with proving it to you. 
The title ‘Architect’ is protected by law (The Architects Act 1980), so that only those who have undergone rigorous
training, and are fully qualified and registered, can rightly use it in any context.
Watch out for companies or individuals styling themselves as ‘architectural designers’ or ‘architectural directors’
or ‘architectural consultants’ or other similar wording as this is generally an indication that they are not eligible
to carry out the work of an Architect.
Other Points to note when selecting your Architect:
• ARCHITECT is a protected title and only a REGISTERED ARCHITECT may use this title.
• It is an offence for anyone who is not a REGISTERED ARCHITECT to pose as an ARCHITECT; or carry
out the work of an ARCHITECT.
• It is an offence for anyone who is not a REGISTERED ARCHITECT to carry out NON-EXEMPTED Works.
• It is an offence for any REGISTERED ARCHITECT to submit works on behalf of an unregistered or
unqualified person.

12

INSTITUTE OF ARCHITECTS ZIMBABWE

THE INSTITUTE OF ARCHITECTS OF ZIMBABWE

The Institute of Architects of Zimbabwe was founded in 1924 as the Institute of Southern Rhodesia Architects
and became legally established by the Architects (Private) Act in 1929. The year 1929 therefore marks the
legal establishment of the now Institute of Architects of Zimbabwe. Its main objects are to promote the art of
architecture and architectural education in the interests of the community and provide full membership status to
Architects who are registered with the Architects Council.
There are various classes of membership open to other than registered architects; graduate, student and
members of associated professions or other individuals with an interest in architecture. The Board of the Institute
meets on a monthly basis to discuss common problems. Since 1957 the Institute has made every effort to see
a School of Architecture established in Zimbabwe and monitors the examination systems of the Architectural
Technician’s courses at the Harare Polytechnic College, Bulawayo Polytechnic College and those set by the
National Association of Architectural Technicians.
The Institute of Architects of Zimbabwe sets professional practice examinations each year for the purpose
of registration with the Architects Council. The Institute holds conferences and lectures on architectural and
related topics.
The first school of architecture in Zimbabwe was established in 1998 in Bulawayo at the National University Of
Science And Technology (NUST).

13

ARCHITECTS’ YEARBOOK

2018 IAZ / ACZ BOARD

INSTITUTE OF ARCHITECTS OF ZIMBABWE BOARD MEMBERS 2018

President: Mr . E. Murwira
Vice-President: Ms R. Musekwa
Mr A. Mandizvidza Ms I. Masiyanise| Mr A. Matondo | Ms T.A.J. Mugedeza ;
Mr. T.R. Manditsera | Mr B. Madondo | Mr G. Cochrane

ARCHITECTS COUNCIL OF ZIMBABWE BOARD MEMBERS 2018

Chairwoman: Ms I. Masiyanise
Vice Chairman: Mr A. Mandizvidza
Mr . E. Murwira Ms R. Musekwa Mr P. Mukura (LGPWH)
Mrs K L Murefu Tshuma (MLGPWH) | Mr A. Matondo | Ms T.A.J. Mugedeza ;
Mr. T.R. Manditsera | Mr B. Madondo | Mr G. Cochrane
Registrar: Mr G. Sheppard

INSTITUTE OF ARCHITECTS OF ZIMBABWE SUPPORT STAFF

Secretariat: Mrs V. Banda
Messenger: Mr A. Gutai

INSTITUTE OF ARCHITECTS OF
ZIMBABWE PAST PRESIDENTS

1925 -1927 J.R. Hobson 1942 - 1943 E. Pallet
1927 -1928 J. A. Cope Christie 1943 – 1944 J.R. Hobson
1928 -1929 D. McGillivray 1944 – 1946 W. D’Arcy Cathcart
1929 - 1930 W. D’Arcy Cathcart 1946 – 1947 R.K. Price
1930 - 1932 D. McGillivray 1947 – 1948 W.E. Alexander
1932 - 1933 J. D. Robertson 1948 - 1949 C.H. Rees
1933 - 1934 F.A.O. Jaffray 1949 – 1951 R.S. Parker
1934 – 1936 J.R. Hobson 1951 - 1952 L. Ayers
1936 – 1937 S. Austin Cowper 1952 – 1954 C. Ross Mackenzie
1937 – 1938 J. D. Robertson 1954 – 1955 A.C. Dold
1938 – 1939 E. Pallet 1955 - 1956 C. Ross Mackenzie
1939 - 1941 J.R Hobson 1956 – 1958 J.L. Gauldie
1941 - 1942 D. McGillivray 1958 - 1960 W.H.G. Stenson

1960 - 1962 R.G.B Wilson 1987 - 1989 S.S. Bais
1962 - 1964 P.L. Oldfied 1989 - 1990 G. Price
1964 - 1965 H.A. Hotson 1990 - 1993 V. Mwamuka
1965 - 1969 R.C. Brown 1993 - 1997 P. Naude
1969 - 1971 R. Densem 1997 - 1999 Standish-White
1971 - 1973 J. Van Heerdan 1999 - 2001 N. Mills
1973 - 1975 J.G. Capon 2001 - 2003 P. Nhekairo
1975 - 1978 P.A Naude 2003 - 2005 J. Dzimwasha
1978 - 1979 R.E. Cooper 2005 - 2007 D. Mandishona
1979 - 1981 H.O. Beck 2007 - 2012 J. McCormish
1985 - 1986 G.M. Mills 2012 - 2014 I. Masiyanise
1986 - 1987 K.B. Lever 2015 - 2017 A.T. Matondo
2018 - E. Murwira

14

INSTITUTE OF ARCHITECTS ZIMBABWE

ARCHITECTS COUNCIL ARCHITECTS
COUNCIL
The Architects Act of 1975 repealed the Architects (Private) Act of PAST CHAIRMEN
1929 and established the Architects Council to provide for the
registration and regulation of the practice of architecture in Zimbabwe. 1976 – 1978 P. Naude
The Council consists of eleven members, nine of which are elected 1978 – 1979 J.A.K. Hope
from the Institute of Architects of Zimbabwe and two appointed by 1979 – 1981 H.O. Baeck
Government. It administers the Act with particular reference to: 1981 – 1986 P.L. Oldfield
1986 – 1989 P. Jackson
1. Registration Requirements 1990 - 1991 V. Mwamuka
— standards are set for academic and professional experience 1991 - 1992 P. Oldfield
which include the passing of the Zimbabwean Professional 1992 - 1993 E. Gurney
Practice examination and a residential qualification. 1993 - 1995 P. Naude (ACZ Chairman
2. Use of Title and Function of an Architect and IAZ President)
3. Code of Professional Conduct 1996 - 2000 P. Oldfield
4. Architects Terms of Engagement and Remuneration 2000 - 2001 P. Jackson
5. The Duties Of An Architect 2002 - 2006 G. Mthupa
– the intention of the Act is to protect the client and the community 2007 - 2008 M.C.R. Vengesayi
from the improper services of a person falsely claiming to be an 2008 - 2011 M.C.R Vengesayi
Architect and from gross negligence on the part of a registered 2012 - 2015 W. M. Kurebgaseka
Architect. The Act clearly states that substantial buildings other 2016 - 2017 A. R. Mandizvidza
than houses and small factories are to be carried out by Architects. 2018 I. T. Masiyanise*

The Council is empowered to hold enquiries and discipline its
members. It may also make recommendations for the promulgation
or amendment of Regulations pertaining to the Act.

15

ARCHITECTS’ YEARBOOK

ARCHITECTURE AS A CAREER

EMPLOYMENT

By its nature Architecture is predominantly an urban skill consequently most architectural firms in Zimbabwe are
located in the major centres. However, with the shift towards rural development and the establishment of rural
growth, it is anticipated that the Architect will be expected to contribute to the physical development of both rural
and urban areas.

Salaries upon qualification have been varying within the past two decades depending on expertise and
responsibilities taken. Excellent opportunities exist in both the private sector and Government for responsible
Architects skilled in handling local materials and geographical and climatic conditions.

QUALIFICATIONS

Before anyone can practice as an Architect in Zimbabwe, as explained later, he has to obtain certain educational
and practical qualifications from a recognised School of Architecture. These qualifications lead to registration as
an Architect under the Architects Act and to membership of the Institute of Architects of Zimbabwe.

PRACTICAL TRAINING

As previously mentioned, most Schools provide a year’s break between the third and fourth academic sessions.
This inter-weaves practice with theory and gives a refreshing contact with real life. The time may be spent in an
Architect’s office or in other sectors of the building industry such as with contractors, manufacturers, quantity
surveyors engineers, planners or in research. After qualification, a continuous period of two years in Zimbabwe,
which may be with different firms but under the direction and control of a registered Architect, is a requirement
for registration as an Architect in Zimbabwe. Similar experience in another country with a registered Architect of
that country will be accepted.

ENTRANCE QUALIFICATIONS

In general terms the minimum entrance qualification for an architectural course is five subjects from specified
fields of the General Certificate of Education (these are set out in detail below), including two passes at Advanced
Level. It is our policy to encourage a diversity of background subjects and to leave the choice of actual GCE
subjects to sixth formers.

If full benefit is to be derived from an architectural course, both Arts and Science subjects should be studied
at sixth form level. In some schools the mix of Arts and Science causes administrative difficulties in relation to
the Advanced level examinations, if this is the case at your school try to keep up with Arts studies if there is only
a “science” sixth form or vice versa if the emphasis in your school is on the Arts. This dual approach forms a
valuable foundation for architectural studies. The Institute of Architects of Zimbabwe would encourage the taking
of craft and technical subjects as a supplement to the basic subjects, but not instead of those listed below.

MINIMUM ENTRY REQUIREMENTS

Some Schools of Architecture have particular requirements in excess of those set out here and you should check
specifically.

The General Certificate of Education

(a) Candidates will be required to have passes in two subjects at Advanced Level of the GCE together
with passes in three other subjects at Ordinary Level.
(b) Both the Advanced Level subjects and at least two lower level subjects must be drawn from
the following fields of study: English, Mathematics, Science, Modern Languages, Classics, History,
Geography, Economics, Music and Art.

16

INSTITUTE OF ARCHITECTS ZIMBABWE

HARARE-WORKINGTON
Cnr Lytton/Douglas Rds,
M+2A6S3V2I4N2G7O53 964-73
+1926G3re2e4n2f7ie72ld0S6t1,
+263 39 262 334-5

17

ARCHITECTS’ YEARBOOK

WE HAVE CHANGED OUR NAME AND
JUST OUR NAME!

From BPB Gypsum Zimbabwe (Gyproc Zimbabwe) to Saint-Gobain
Construction Products Zimbabwe (Private) Limited.

Since 1959, we have supplied Zimbabwe with premium construction
products, helping you to turn your dreams to reality! As we step into
the future, we promise to continue to give you the best of the best;
providing you with world-class brands with unmatched quality you
know and trust.

18Contact: +263 772 101 752/ +263 772 231 540/ +263 8677004817 www.facebook.com/gyproczimbabwe.zimbabwe

youtube channel:Saint-Gobain Gyproc Zimbabwe

INSTITUTE OF ARCHITECTS ZIMBABWE

(c) The following subjects are usually compulsory:
English Language.
Mathematics or a Science subject
These compulsory subjects may be taken at either Advanced or Ordinary Levels.

EXAMINATION IN PROFFESSIONAL PRACTICE

One of the requirements for registration as an Architect in Zimbabwe is to pass a written an oral
examination in professional practice as it applies in Zimbabwe. The examination is administered by the Institute
of Architects of Zimbabwe and approved by the Architects Council.

The written examination is of three hours’ duration and candidates are required to answer five questions under
the headings: Professional Conduct; Conditions of Engagement; Model Building By-Laws; Town Planning
Legislation and Contractual Procedure. The examination is an “open book” examination and candidates may
consult any of the literature mentioned below during the examination.

Following the written examination, candidates will present themselves for an oral examination at a time to be
fixed some days after the written paper. Candidates will be asked to qualify their answers where necessary and
anything else within the scope of professional practice, and are required to bring examples of their work. The oral
examination, which is an examination in its own right, carries the same marks as the written paper and the pass
mark for each is 60%.

The examination is based on the following reading –
Architects Act No. 35 of 1975
Architects (General) By-laws 1976 (RGN 296/76)
Architects (Amendment) By-laws 1980 (SI 333/80)
Architects (Professional Conduct) Regulations 1976 (RGN 810/76)
Architects (Conditions of Engagement and Scale of Fees) By-laws 1980 (SI 829/80)
Model Building By-laws 1977
Model Building (Amendment) By-laws 1985 (SI 310/85)
Town Planning Court Rules 1971
Regional Town and Country Planning Act 1976
RTCP (Use Groups) Regulations 1976
RTCP (Subdivison and Consolidation) Regulations 1976
RTCP (General Development) Order 1976
RTCP (Development) Regulations 1976
RTCP (Advertisements) Regulations 1977
RTCP (Claim for Compensation) Regulations 1977
RTCP (Mater and Local Plans) Regulations 1977
Factories and Works Act (Chapter 283)

Which are obtainable from Dorking House

And,
Agreement and Schedule of Conditions of Building Contract (where Bills of Quantities form part of the contract)
Agreement and Schedule of Conditions of Building Contract (Lump Sum)

Which are obtainable from the Institutes offices.

The examination is held annually towards the end of each year, the fee for which is $175.00. In special cases
where it is shown that hardship would otherwise occur, the Council may, at its discretion, set a special
examination for which the fee is $350.00.

Application forms and past papers are available from the Institute’s offices.

19

ARCHITECTS’ YEARBOOK
20

INSTITUTE OF ARCHITECTS ZIMBABWE

GUIDELINES FOR REGISTRATION
REQUIREMENTS IN ZIMBABWE

1. Any person who wishes to perform the work of an Architect as a partner or principal in the private practice
in architecture is required to register in terms of the Architects Act 1975, of which copies are available from
Government Printers or the Government website.

The Act describes the work of an Architect as –
(a) The designing of building or additions thereof
(b) The supervision of the work of constructing buildings or of additions thereto.

2. Section 40 of the Act permits an unregistered person who is in bona fide employment of a registered Architect to
perform the work of an Architect under the direction and control of such registered Architect.

3. The provisions of the Act do not apply to any person in the employment of the State or Local Government, who
are controlled by their own terms of employment. Government and municipal Architects are however encouraged
to become registered.

4. Section 39 of the Act says, inter alia, that a person who is not a registered Architect may not perform the work of an
Architect for gain or use a description that is calculated to convey that he is a registered Architect.

5. The Second Schedule of the Act describes persons who qualify for registration as –
1. A person who –
(a) Is of or over the age of twenty-one years; and
(b) Is ordinarily resident in Zimbabwe; and
(c) Has passed an examination prescribed by the Council or any examination recognized by
the Council as being equivalent to one so prescribed; and
(d) Has, for a continuous period of two years, performed –
(i) The work of an Architect under the direction and control of and in the same office as a
registered Architect or an Architect referred to in subparagraph (b) of paragraph 2; or
(ii) Architectural work which in the opinion of the Council is of sufficient variety and of a
satisfactory nature and standard for the purpose of registration as an Architect
2. A person who –
(a) Is ordinarily resident in Zimbabwe; and
(b) Immediately before the appointed day (1 March 1976) was a duly registered member of the
Rhodesian Architects established by Section 3 0f the Achitects (Private) Act (Chapter 208).

6. In order to meet the above requirements, a person wishing to apply for registration should be prepared to
furnish the following information:
(a) Birth certificate or certified copy
(b) Proof of residence in Zimbabwe by means of certified documentary evidence. The applicant must have
proof that he or she resides in Zimbabwe and no other country, by means of a permanent address,
terms of employment, place of birth entry into the country, I.D. Card, etc., and may be required if there is
doubt to provide a sworn affidavit. In the case of a new resident, a Work Permit or similar document
issued by the Immigration Authorities is essential.
(c) An original certificate of any qualification which is relied upon for registration, or a certified
copy. The examinations prescribed (for the purposes of subparagraph (c ) of paragraph 1 of the
Second Schedule) shall consist of:
(i) A degree or diploma of any School of Architecture which entitles the holder to register
as an Architect in the country or state of issue, subject to a requirement for a period of
practical experience, and
(ii) A written and oral examination administered by the Institute of Architects of Zimbabwe and
approved by the Architects Council.
(d) Certified evidence to prove that the applicant has performed the work of an Architect as required by
5.1.(d) (i) above for a continuous period of two years or certified evidence by way of drawings or
photographs that the applicant can meet the requirements of 5.1.(d)(ii) above. Council prefers and
recommends that at least six months experience of local practice conditions is necessary before taking
the Professional Practice examinations.

21

ARCHITECTS’ YEARBOOK

GUIDELINES FOR TEMPORARY REGISTRATION

ARCHITECT’S ACT 1975

Foreign architects who undertake an architectural commission in Zimbabwe are required to take out temporary
registration with the Architects Council.
The requirements are as follows:

1. Any person who has, in the opinion of the Council, been bona fide engaged to perform the work of an Architect
in a Consultative capacity and who is not ordinarily resident in Zimbabwe, is over the age of’ twenty-one and
possesses an approved architectural qualification and has had at least three years’ experience, may apply for
temporary registration which can be renewed annually (Section 27 of the Architects Act 1975 refers. The fee per
partner or principal in control of the project is $ 1000 per annum.

2. Temporary registration is linked and restricted to one project only and the applicant is required to be in
association with a registered Architect for that project. Persons who are temporarily registered may not enter into
general practice and may only be concerned in that particular project. Temporarily registered persons are subject
to the provisions of the Architects Act and Regulations as is a fully registered person. Your attention is drawn to
the fact that a registered person may not “tout” for business in terms of Section 4 of RGN 810 of 1976 “Architects
(Professional Conduct) Regulations”

3. In order to meet the above requirements, a person not wishing to apply for temporary registration should be
prepared to furnish the following information:
(a) Documentary evidence of place of residence.
(b) Documentary evidence of date and place of birth.
(c) An original certificate of any qualification which is relied upon for registration, or a certified copy.
(d) Certified evidence by way of curriculum vitae, drawing or photographs that the applicant has
met the requirements.
(e) Details of the project in Zimbabwe with which the applicant is involved.
(f) Letter of association on the project between the applicant and a registered Architect, signed by
the latter.

THE PROCEDURE FOR REGISTERING AS AN ARCHITECT AND
JOINING THE INSTITUTE OF ARCHITECTS OF ZIMBABWE

1. Apply to the Secretary/Registrar of the Architects Council to sit the examination in Professional Practice,
supporting the application with documentary evidence as required in paragraph 6 of Guideline’s for Registration
by Requirements in Zimbabwe.

2. On passing the Professional Practice Examination, Complete the form Application for Registration as an
Architect (AG1) following the requirements of the Architects (General) by By-laws 1976, section 3, and section
16(1) of the Architects or Act 35/75, and submit to the Secretary/Registrar.

3. Registered Architects may then complete the form for Application for membership of the Institute of Architects
of Zimbabwe, and submit it to the Secretary.

4. Persons applying for temporary registration may apply for membership of the Institute of Architects of
Zimbabwe concurrently.

5. All Architects in full time bona fide employment with the State or Local Government are eligible to apply for full
membership of the Institute of Architects of Zimbabwe subject to proof of academic qualifications and verification
of employment with such organizations. Such members will not be liable to the Practice levy.

All forms are available from the Institute’s offices at Dorking House.

22

FEES INSTITUTE OF ARCHITECTS ZIMBABWE

Architects Council $ There are four classes of Associate Member

Temporary Registration Fee (a) Student Members – persons undergoing a course
of study approved by the Board.
(for one year only, renewable) 7000,00 (b) Graduate Members — persons who hold a
qualification in architecture approved by the
Registration Fee 750,00 Architects Council for registration, but are not
registered.
Annual Subscription 750,00 (c) Affiliate Members — persons or body of persons
who have affiliated architectural interests.
Institute of Architects of Zimbabwe (d) Retired Members — persons who have been
members of (he Institute for at least five years
Entrance Fee 250,00 and have retired from practice.

Annual subscription 250,00 Associate membership is intended for those persons
who are not registered architects under the terms
FEES $ 20,00 per annum of the Architects Act 1975 and therefore may not
$50,00 per annum perform the work of an Architect.
Student membership $200,00 per annum
Graduate membership $100,00 per annum No Associate Member is entitled to vote at any
Affiliate membership General Meeting or to nominate or second any
Retired Membership candidate as a member of the Board or to cast his
vote for any such candidate, nor shall he be eligible
for nomination or election as a member of the Board.

WE MANUFACTURE TOP QUALITY PALISADE
SECURITY FENCING IN ZIMBABWE

We specialise in 1.2m high, 1.5m high, 1.8m high and 2m high Locally Manufactured in Zimbabwe!!!
palisade fencing. We make other heights as per client request.
Standard panel sizes range between 2m spans and 2.5m spans. Green Eye Marketing (Pvt) Ltd ta Tesa Fencing
Customer requests are also considered. 3 Cardiff Street Belmont, P.O. Box 8103 Belmont, Bulawayo, Zimbabwe

Tele/Fax +263 9 72703/70388
Email - [email protected]/ [email protected]

VENDORS ROLL NUMBER - 710787
STATE PROCUREMENT REGISTERED
COMESA REGISTRATION - HQ/44/COM/2282

CIFOZ REGISTERED

23

Find Us on Facebook: https://www.facebook.com/tesafencing | Website: http://tesazimbabwe.com/

ARCHITECTS’ YEARBOOK

104 Seke Road, Graniteside, Harare
email: [email protected], call:758 071-3/ 755 558
ww24w.flint.co.zw

INSTITUTE OF ARCHITECTS ZIMBABWE

ARCHITECTS (CONDITIONS OF ENGAGEMENT AND
SCALE OF FEES) BY-LAWS

S.I.829 of 1980 (As amended by S.I.222 of 1994 & S.I.110 of 2013)

PRELIMINARY

TITLE
1. These by-laws may be cited as the Architects (Conditions of Engagement and Scale of Fees) By-laws, 1980.

INTERPRETATION OF TERMS
2. In these by-laws –
“Architect” means a person registered as an Architect in terms of the Act;
“building” means any building or proposed building , an includes any alteration of, or addition to, an existing
building.

PART 1

GENERAL DUTIES OF ARCHITECTS
GENERAL DUTY
3. In addition to the duties imposed by these by-laws, it shall be the duty of an Architect to advise his
client on, and to prepare, the design of any proposed building and, if so required by his client, to
supervise the construction of the building and to provide such additional services referred to in these
by-laws as may be required by his client.

SUBCONTRACTORS
4. (1) An Architect may recommend to his client that a specialist subcontractor be engaged for the
4. (2) Where a subcontractor is engaged by his client, an Architect unless it is otherwise specifically
agreed, shall –
4. (2)(a) be responsible for the direction, integration and general supervision of works executed by the
subcontractor; and
4. (2) (b) ensure that the subcontractor accepts sole responsibility for any design undertaken by him.

VARIATIONS AND EMERGENCIES
5. (1) An Architect shall ensure that –
5. (1)(a) before initiating any stage of his duties referred to in Part II, he has the necessary authority
of his client; and
5. (1)(b) before deviating in any material respect from a design approved by his client, he has the
consent of his client thereto:
Provided that, if any such alteration is necessary as a matter of urgency for constructional reasons
or on order to comply with any enactment, the Architect may authorize such alteration, and shall
inform his own client thereof without delay.
5. (2) Where an Architect becomes aware of any likely variation of expenditure authorized by his client
or the estimated period within which any work for his client will be completed, it shall be his duty to
inform his client thereof forthwith.

SUPERVISION
6. Where an Architect is required to supervise the construction of any work, it shall be his duty
to give such periodic supervision and inspection of the work as is necessary to ensure the proper
execution of the work in accordance with the provisions of contracts relating thereto, but, unless it is
otherwise agreed, constant supervision by the Architect shall not be required.

25

ARCHITECTS’ YEARBOOK

RESIDENT ARCHITECT
7. Where an Architect has agreed with his client that a resident Architect should be employed in order
to provide constant supervision of any works, the Architect shall, unless it is otherwise agreed, be
responsible for the employment of the resident Architect and for his remuneration on a time basis in
terms of section 15, which shall be recovered from his client.

CLERK OF WORKS
8. Where a clerk of works is to be engaged by his client, the Architect shall recommend the
appointment of a suitable person, and shall advise that any person so engaged will be employed by the
client, under the management of the Architect, an remunerated by the client.

CONSULTANTS
9. Where a consultant is engaged by his client, an Architect shall, unless otherwise specifically agreed –
9. (a) make it clear that the consultant is responsible for the work entrusted to him
9. (b) advise the client that the payment of the fee of the consultant is the responsibility of the client.

COPYRIGHT IN PLANS, ETC
9A. Before concluding a contract with his client, an Architect shall ensure that the contract makes provision
for the vesting of copyright in any plans, drawings and other work done in pursuance of the contract.

LIMITATIONS OF ARCHITECTS LIABILITY
9B. An Architect shall ensure that in any contract he enters into with his client, his liability for negligence
or other misconduct in the course of his professional duties is limited to a five year period after –
9B.(a) completion of the work done under the contract; or
9B. (b) occupation of the building to which the contract relates; whichever is the latter:
Provided that no such limitation shall apply to the architect’s liability for design defects which endanger
human life.

PART II

SPECIFIC DUTIES OF ARCHITECTS

PROJECT
10. Before preparing working drawings for his client, it shall be the duty of an Architect to –
10 (a) hold preliminary discussions with his client for the purpose of determining the requirements
and scope of the commission;
10 (b) prepare a brief, outlining the requirements and planning proposals including the necessity or
otherwise of appointing any specialist consultant or clerk of works:
10 (c) advise on the form in which the project is to proceed
10 (d) advise on town planning and building by-law legislation and on the financial limitations set
by the client,
(e) prepare design drawings, which snail show the general layout, design, construction, outline
specification and costs of the work sufficient for the purpose of obtaining the approval of the client.
10 (f) obtain the approval of his client of the design, specification, construction and cost of the work
before proceeding to working drawings.

CONTRACT
11. The Architect shall proceed to contract stage as follows —
11 (a) prepare working drawings, details, schedules arid other documents necessary for the complete
carrying out of the works; and
11. (b) co-ordinate the work of any specialist consultants employed, and supply them with all
information required by them to complete their part of the work, and
11. (c) ensure that all necessary by-law and other building approvals have been received; and
11 (d) call for, and receive, any tenders required, and advise on their acceptance; and
11 (e) prepare for signature any contract documents required in connexion with the work; and
11 (f) select and recommend a suitable person for appointment as clerk of works

26

G ROGOQFRIUONIAONGLQFISIAUNTATNYGLIDTAIATPUNNYIPDTDAIENPSNGIEPODRISNFVSOGEIALCRUSERVTOICIOLCUNHETSIIOTNESCTS ZIMBABWE

YEARS

7755YEARS
STSTtitililielllelNTNTeueucmchmhnbnboeoerlrolo11ggIyInyn CELECBESRLTEARBTISRETNANRTGIGEN7TN5GHGYI7TE5NHAYIPRESRNAOOPRFDSRUOOOCFFDTFEUORCIFTFNERINSINCE1943
C E1 94 3
RRSSAARRYY I
AANNNNI VI VE ES N

BBeeststPPrircicee
BBeeststQQuuaaliltiyty
ZZeeroroLoLoaaddiningg
CChhaargrgee

Available in these colours
Available in these colours

Turnall Harare Head Office Turnall Bulawayo
Tur5nGalal sHgaorwarReoHaeda, dP.OOf.fBicoex 3985 TurSnteaelllBWuolarkwsaRyooad
5 GWlaosrgkoiwngRtoona,dH, Par.Oar.Beo, xZi3m9b8a5bwe StePe.lOW.Boorxks17R5o3ad
WoTrekli:n(g0t4o)n7, 5H4ar6a2r5e/,9Z, i7m54ba6b3w0/e1 P.OB.Buloaxw1a7y5o3, Zimbabwe
TelF: a(0x4: )(0745)47652456/392, 754 630/1 BulTaewl:a(y0o9,)Z8i8m2b2a3b0w-e7
FaxS:a(l0e4s)T7e5a4m6:302712 412 855, TelF: a(0x9: )(0898)28283202-378-9
Sal0e7s1T2e4a1m1:003771,2074172 780525,441 FaxS:a(l0e9s)T8e8a2m2:380-7912 420 635,
071027142114106377,903717 702 441 Sal0e7s1T2e4a0m5:9200712 420 635,
0712 416 793 0712 405 920

Midlands: 0712 405 920
MidVlaonipdHs:r0e7: 1028460757090240874 . Voip Byo: 08677004875
Voip Hre: 08677004874 . Voip Byo: 08677004875

27

Turnall Holdings +263 712 420 637 [email protected] www.turnall.co.zw
Turnall Holdings +263 712 420 637 [email protected] www.turnall.co.zw

ARCHITECTS’ YEARBOOK

SUPERVISION
12. Where an Architect is required to supervise the construction of any works, he shall be responsible
12 (a) for approving the programming for the progress of the work set by the contractor; and
12 (b) until the works are completed, for making such periodic visits to the site as may be necessary
to ensure that the provisions of the contract relating to the construction of the works are fulfilled,
co-ordinating the work specialist consultants, and issuing any certificates of progress or other
certificates which may be required; and
12 (c) for rendering such assistance as may be required to the contractor in handing over the building
to a client in a state suitable for occupation; and
12 (d) for presenting the final accounts relating the work.

PART III

FEES CHARGEABLE
13 (1) The fees provided in this Part shall not be lower than the scale and variations referred to in the First,
Second, Third, Fourth and Fifth Schedules.
13 (2) The Architect shall inform his client and obtain formal acceptance, before he renders the service
concerned, of the fees which he intends to charge, whether the fees are in excess of those referred to in
subsection (1) or not.

GENERAL FEES
14 (1) Subject to the provisions of this Part, the fee for designing and supervising the construction of
any building shall be a percentage of the final cost of the works according to the fee scale shown
in the First Schedule and the variations to it as shown in the Second Schedule.
14 (2) The final cost of the works shall include the cost of the mechanical, electrical and other
services which are an integral part of the design.
14 (3) The fees referred to in the First and Second Schedules shall be calculated in accordance with
the provisions of the Schedules on the percentage of –
14 (3) (a) the final cost of the completed work; or
14 (3)(b) when payments are to be made before the final cost can be ascertained -
(i) an estimate by the Architect or quantity Surveyor for the complete work;
(ii) the lowest bona fide tender for the complete work, excluding any amount in that tender in
respect of contingencies, if no contract is entered into;
(iii) the contract sum
Provided that, when work is executed wholly or in part with old materials or where material
labour or carriage is provided by the client, the percentage shall be calculated as if the works had
been executed wholly by a contractor supplying all labour and new materials at such rates as

were applicable at the time when the work was executed
14 (4) The fees payable an respect of any stage of the work of an Architect shall be calculated
according to the provisions of the Third schedule, which the Architect may require to be paid at the
end of the appropriate stage except the fees for preparation of the brief, which shall be payable on

the acceptance of such services:
Provided that, in the case of a large contract, the Architect may require interim payments to be made.
14. (5) Where the work of an Architect relates to buildings which fall into more than one category, the
fees shall be calculated in accordance with the provisions of that section in respect of each category.

CHARGES ON A TIME BASIS
15. Where any fees or charges are to be calculated on a time basis they shall be calculated according
to the provisions of the Fourth Schedule

WORK NORMALLY PERFORMED BY SPECIALIST CONSULTANT
16 (1) The fee referred to in section 14 shall not cover work performed by an Architect which is
normally performed by a consultant
16 (2) Where an Architect, at the request of his client, performs work which is normally performed by
a consultant, he shall charge for that work in accordance with the scale of fees normally charged

28

INSTITUTE OF ARCHITECTS ZIMBABWE
29

ARCHITECTS’ YEARBOOK

by members of the professional body concerned.

PROJECTS COMPRISING TWO OR MORE CONTRACTS
17. Where a project undertaken by an Architect is covered by two or more contracts, the fees shall be calculated
separately in respect of the work covered by each contract,

PARTIAL SERVICES OR COMMISSIONS
18 (1) Where an Architect provides only part of the services normally provided by an Architect, the fee
for that part shall be calculated on a pro rata basis
Provided that, if only a part of the normal service on any stage is provided, the fee for that part shall be calculated
on a time basis in terms of the provisions of the Fourth Schedule
18 (2) Where an Architect has been paid his fee in respect of a commission which has been
terminated or deferred, if that commission is subsequently resumed

WORK NORMALLY PERFORMED BY SPECIALIST CONSULTANT
16 (1) The fee referred to in section 14 shall not cover work performed by an Architect which is
normally performed by a consultant
16. (2) Where an Architect, at the request of his client, performs work which is normally performed
by a consultant he shall charge for that work in accordance with the scale of tees normally
charged by members of the professional body concerned.

PROJECTS COMPRISING TWO OR MORE CONTRACTS
17. Where a project undertaken by an Architect is covered by two or more contracts, the fees shall be
calculated separately in respect of the work covered by each contract.

PARTIAL SERVICES OR COMMISSIONS
18 (1) Where an Architect provides only part of the services normally provided by an Architect, the fee
for that part shall be calculated on a pro rata basis:
Provided that, if only a part of the normal service on any stage is provided, the fee for that part
shall be calculated on a time basis in terms of the provisions of the Fourth Schedule.
18 (2) Where an Architect has been paid his fee in respect of a commission which has been
terminated or deferred, it that commission is subsequently resumed
18 (2) (a) without substantial alteration within two years of termination, the fee so paid to him shall
be regarded as payment on account toward the total fee due, based on the final costs of the
project; or
18 (2) (b) with substantial alteration, whether caused by changed statutory conditions or otherwise
within two years thereof, or after a lapse of more than two years, the commission shall be
regarded as a new one, unless the Architect and his client agree that the additional work shall
be charged on a time basis in terms of the provisions of the Fourth Schedule
18. (3) Where work which has been included in the original building contract has subsequently been
omitted, the fee chargeable shall, notwithstanding such omission, be seventy-five per centum of
the final fee calculated in terms of this Part in respect of the work included in the original
building contract.
18 (4) Where one Architect is commissioned to take over work which was not completed by some
other person during or after any of the stages detailed in the Third Schedule, he shall, for his
professional services, charge a minimum fee calculated in accordance with the provisions the
First Schedule, increased by a surcharge or twenty per centum on each of the stages still to be
completed.

TRAVELLING AND SUBSISTENCE CHARGES
19 (1) Where an Architect requires payment in respect of any transport expenses incurred by himself
or by an employee of his, they shall be calculated as follows –
19. (1) (a) in respect of travel by air, rail, sea, hired or fare-paying vehicle, the actual cost of the fare;
19. (1) (b) In respect of transport by motor-vehicle, the rate fixed from time to time by the council.
19 (2) Any charge made by an Architect in respect of subsistence whilst he or his employee is away
from his ordinary place of residence shall be calculated on the basis of the actual incurred by
himself or his employee, as the case may be.

30

INSTITUTE OF ARCHITECTS ZIMBABWE

19 (3) In addition to travelling and subsistence charges in terms of subsections (1) and (2), an
Architect may charge according to the circumstances on a time basis in terms of the provisions of
the Fourth Schedule in respect of the hours, including time caused by delays, during which
he or his employee as the case may be, is absent from his ordinary place of business or residence
whichever is applicable
19 (4) Except by prior arrangement with the client, the charges in terms of subsections(1). (2) and (3)
shall be based on reasonable costs, having regard to the nature of the journey involved

EXPENSES
20 In addition to the fees referred to elsewhere in this Part, an Architect shall recover from his
client the charges for any of the following expenses which he has incurred on his behalf -
20 (a) printing and reproduction of any document, map, model, photograph or other record for
communication to and between consultants, the clients, contractors, subcontractors and suppliers;
20 (b) telephone trunk calls and cables;
20 (c) excessive postage on packets or parcel delivery;
20 (d) the cost of any research, test investigation specialist advice and advertising for tenders which
has his clients approval,
20 (e) fees payable to local authority or Government department, any search fee and any
similar disbursements.

VALUATION OF BUILDINGS
21. Where an Architect makes a valuation for the replacement of any building, the fees charged by
him shall be in accordance with the provisions of the Fifth Schedule with a minimum fee of
two hundred dollars, exclusive of any expenses or changes mentioned in section 19.

ARBITRATION FEES
22. Where an Architect is appointed as an arbitrator for any dispute in terms of these by-laws,
he shall charge –
22 (a) if there is more than one arbitrator, on a time basis in forms of the provisions of the Fourth Schedule
22 (b) if he is the sole arbitrator, on the basis of two hundred dollars per hour, with a minimum of two
hundred and forty dollars.

EXPERT WITNESS
23. Where an Architect is called to give evidence before any court or tribunal as an expert witness,
he shall charge on a time basis in terms of the provisions of the Fourth Schedule, depending on the complexity of
the problem.

FEASIBILITY STUDIES
24. Where an Architect undertakes, on behalf of a client, feasibility studies involving a preliminary technical or
economic appraisal of a project in order to enable the client to decide whether and in what form he shall proceed
with the project, he shall charge an additional fee for such studies, which shall, unless otherwise agreed with
the client, be calculated on a time basis in terms of the provisions of the Fourth Schedule, depending on the
complexity of the problem.

SPECIALIST AND OTHER SERVICES
25. Where an Architect undertakes any of the following services, the services shall be agreed to and defined in
writing, and remunerations therefore shall be in addition to the fees elsewhere enumerated in this Part, and shall
be calculated on a time basis in terms of the provisions of the Fourth Schedule –
25. (a) advising as to the selection and suitability of the site;
25. (b) negotiations as to the site and buildings, if any;
25. (c) the preparation of additional drawings necessitated by a material alteration in, or in addition
to, the client’s instructions, or altering the working drawings and specification in consequence
thereof prior to the commencement of work;
25. (d) altering drawings or preparing new drawings and promoting other services involved in
Consequence of variations or additions required by the client after the commencement of work;
25. (e) making extra drawings for the client’s or contractor’s use, drawings for and negotiating
with landlords, tenants, adjoining owners, public authorities, licensing authorities, or other
services in respect of servitudes, litigation, arbitration or valuations, bankruptcy, negligence of
parties, force majeure;

31

ARCHITECTS’ YEARBOOK

25. (f) any survey or investigation of an existing building;
25. (g) any inspection of building work in progress not referred to elsewhere in the regulations;
25. (h) any specialist consultant architectural services, including the design of residential, industrial
or commercial layouts;
25. (i) any interior or furniture specialist joinery design, shop fittings or exhibition work

WORK OUTSIDE ZIMBABWE

26. Where an Architect engages to perform work in respect of a building to be erected outside Zimbabwe, he shall,
in respect of the work undertaken outside Zimbabwe, adhere, as far as possible to the fees provided for in this Part.

EXTRAORDINARY FEES

27. Where an Architect undertakes any services for which fees are not adequately provided in this Part, he shall
apply to the council for guidance in respect of the fees which he should charge.

PART IV

GENERAL

TERMINATION OF AGREEMENT
28. An Architect shall ensure that any agreement entered into with clients provides for –
28. (a) the termination thereof at any time by either party on the giving of reasonable notice; and
28. (b) the remuneration of the Architect in accordance with the provisions of Part III for services
rendered prior to the termination of the agreement.

DISPUTES
29. An Architect may agree with his client that any difference or dispute which they may have shall be referred
to the council for a ruling, subject to the following provisions –
29 (1) (a) the reference shall be by way of submitting a joint statement of undisputed facts, plus
separate statements of disputed facts;
29 (1) (b) the Parties shall agree in writing to accept the ruling of the council as final and not subject to appeal,
29 (2) An Architect shall ensure that in his agreement with his client, provision is made that where
any difference or dispute arising out of the requirements of these by-laws cannot be determined
in accordance with the provisions of subsection (1). It shall be submitted for arbitration by a
person agreed between the parties and that —
29 (2) (a) either party may give to the other a written request to agree on the appointment of an arbitrator
29. (2)(b) if, after fourteen days from the request referred to in paragraph (a), there is no agreement,
the chairman of council may, at the request of either party, nominate an arbitrator.

REPEAL
30. The Architects (Conditions of Engagement and Scale of Fees) (Amendment) By-laws. 2000 (No. 5), published
in Statutory Instrument 3210 of 2000, are repealed.

FIRST SCHEDULE (Section 14)

THE FEE SCALE

N.B. This scale and the Schedules refer to the lowest fees which may be charges by an Architect for his services,
for which his client’s formal acceptance is required. See subsections (1) and (2) of section 13.

32

INSTITUTE OF ARCHITECTS ZIMBABWE

SECOND SCHEDULE (Section 14)

VARIATION OF FEE SCALE

Type of building Fee
The fee scale +30 per centum
Dwelling - house The fee scale + 20 per centum

Hospitals, nursing homes, clinics, laboratory The fee scale, but may be reduced by not more
complexes or similar buildings requiring extensive than 20 per centum, depending on the proportion of
specialized services open repetitious or storage space
Fourth or Third Schedule by agreement
Industrial buildings where the Architect is the
principal agent

Industrial buildings where the Architect is not the
principal agent

HOUSING SCHEMES –

(a) For each prototype building in detached, semidetached, terraced or flatted form
(b) For identical repetitions of (a) and reuse of documentation without site-and-service drawings
(c) Supervision of (b)
(d) Site-and-service plans
(e) Design of general layout, modifications to the drawings and documents of (a)
(f) Landscaping, sewerage and road works
Alterations and additions to existing buildings

THE FEE SCALE –

One per centum of contract cost or estimated cost
Third Schedule, 1.5 per centum of contract cost
Six per centum of site-and-service costs per unit
Fourth Schedule time charges

As consultants
The fee scale + up to 50 per centum, at Architect’s discretion, depending on circumstances

THIRD SCHEDULE (Section 14(3))

FEES BY STAGES

PROJECT
Twenty-five per centum of total fee, made up as follows –
(a) Brief: five per centum of total fee
(b) Preliminary design: ten per centum of total fee
(c) Final design: ten per centum of total fee

CONTRACT
Fifty per centum of total fee
Working drawings, schedules and contract documentation

33

ARCHITECTS’ YEARBOOK

eProPproenpretrytyMMaannaaggetmemenet nt P

Property Management
Ta
Em
W
Em
Ph

e| rPtroperPtyyInvestment |rProMpeorty Developmepnt a| PropertyeMnanag

peePropertPyproInrpveertsytImnveenstttme|rnPt r|oiPpreorpoteyrteDy eDveevelozloipmpmmreeppnntrsto|p| PePrrotrpioeepsrte.ycrMto

34

zziimmrreepproropepreti

INSTITUTE OF ARCHITECTS ZIMBABWE

ent PrPorpopeerrttyVVaaluluataiotnion
mMeantnagePmroepnetrty V+2P6a3r7l7o3u4p0a6 5te99irotny Va
Tawanda Manyadza – Mobile:
TawaEnmdaail: [email protected]–pMertoiebs.izleim: r+e.2co6.3zw773 406 599
WEEmmoaaniiEWPdll::mheotwoarnmnimdlTWEEM:eaeammw:anrowa+mvaanMy2vaiieadall6a::[email protected]@[email protected]––ozuda9rrapdMozdMo,@[email protected]–loi–riee1eritp:lMo5ssMieee+.p7.oz:ros2z,etiTEEWbmbi+6.ir7eamimmzti3l7ro2slieweeei7.aam:rn76:.szae2cii7+d.ill3+m::r0onz.32ee2ci7.twdmrz67rm06.oeawcm337r3M..a[email protected][email protected]–o4–9rpMoMeporoetbbireitilslie
eProperrtyPMhaonntaeg:em+Pe2hyn6ot3n|e4:P+r7o27p67e3r1t4y37V97a,l7u71Ma73ti97o,n17s5P77|7h,1oP57nr7o7e,p:7e7+2r7t207y627S30aa74les777139, 7n77

pentp|yt erP|MorpPoaeprnoerpatrietgeyretsDym.ceMveoaen.nrlzotawpg|memPenertontp|te|PrPrtoyropVpeeartrliytuyaMVtaaionlunaaegstieomn| sePn|rtoP|proePprretoyrpstySerSatyaleleVssaluati

emrtrieepsro.cpoer.tziews.co.zziwmreproperties.co.zw 35

ARCHITECTS’ YEARBOOK

SUPERVISION

Twenty-five per centum of total fee
Issuing interim and final certificates, architects instructions and further drawings

FOURTH SCHEDULE (Section 15)

Partners of Principals > 10 years experience One hundred and thirty-two dollars (US$132,00) per hour
Salaried Staff (Architect) < 10 years experience Ninety dollars (US$90,00) per hour
Technical Staff
Forty-five dollars (US$45,00) per hour

FIFTH SCHEDULE (Section 21)

Not exceeding $200000 $1 per $1000
Exceeding $200000 but not exceeding $500000 $200 plus 50c per $1000 in excess of $200000
Exceeding $500000 but not exceeding $1 000000 $350 plus 37 1/2c per $1000 in excess 01 $500000
Exceeding $1000000
$550 plus 25c per $1000 In excess $1000000

The Memorandum of Agreement between client and architect is available from the
Institute Offices for $50,00

36

INSTITUTE OF ARCHITECTS ZIMBABWE

Providing Steel Solutions for:
Agricultural Sheds

Advertising Billboards
Horticultural Greenhouses
Industrial Sheds/ Warehouses

Poultry Houses
Tobacco Tunnels
74 Woolwich Road, Willowvale, Harare
[email protected]
+263 - 712 221 207

37

ARCHITECTS’ YEARBOOK

DIRECTORY OF ARCHITECTS

AHMED I

9 Dunmore Avenue
Queensdale
Harare
Tel: 0772 933 074

Arch. Ahmed I.

Amandiz CBZ Wealth Management Centre Borrowdale
Architect

50 Van Praagh
Milton Park
Harare
Tel: 757884/5 704003
Cell: 0712 408 293/0784 448 229
e-mail: [email protected]

Arch. Mandizvidza A. B Arch (UCT)
Arch. Mutereko M. BAS ,B Arch (NUST)

Apex Design

613 Gweuma Crescent
Victoria Falls
Tel: 0712 434 303
e-mail: [email protected]

Arch. Chitolo L B Arch (Copperbelt)

38

INSTITUTE OF ARCHITECTS ZIMBABWE

Arch-Design

34 Bradfield Road
Hillside
Harare
Tel: 772103/4 0772 340 837
e-mail: [email protected]

Arch. Madavo C. B Arch (Lahore)

Archi-Craft

5 Beryl Drive
Greendale
Harare
Tel: 04-448320/ 0772 694 969
e-mail: [email protected]

Arch. Matondo T.A. B Arch.

Archiplan Architects

19 Natal Road (gate from East Road)
Avondale. P.O. Box 5105 Harare
Tel: 334752/ 334142/ 332045
Cell: 0712 608 5I9
e-mail: [email protected]

Arch. Tvrtkovic M Dip Arch
Arch. Gacic M Dip Arch (Belgrade)

TELECEL HQ , Seke Road, Harare, ZIMBABWE
39

ARCHITECTS’ YEARBOOK

Architecton Design Studio

12 Murandy SquareEast,
Newlands Shopping Centre, Harare
Tel: 0774 165 250
e-mail: [email protected]

Arch. Mukaratirwa H. MSc Arch (Poland)

Architects Design Centre

7 Malvern Road
Mount Pleasant, Harare
Tel: 702384/5 703487
Cell: 0772 410 334
e-mail: [email protected]

Arch. Mashakada B Arch (New Castle-Upon-Tyne)

House Gwinyai, Folyjohn Crescent, Harare

Architectural and Planning
Studio (APS)

25 Shorthheath Rd
Chisipite, Harare
Tel: 0772143314 / 0779659597
e-mail: [email protected]

Arch. Claypole M N B Arch (Natal) SACAP
Arch. Cochrane G BAS (UCT) M Arch (PE)
Arch. Fox G. BAS, M Arch (UCT) SACAP

Megahey Learning Resource Centre, Peterhouse Group of Schools, Marondera

40

Architrave Design Group INSTITUTE OF ARCHITECTS ZIMBABWE

4 Hill Road ARIPO Headquarters, Harare
Highlands, Harare
Tel: 443311 /496254/08644207960
Cell: 0772 232 185
e-mail: [email protected]

Arch Kanyanta C B B A Honors Arch, Dip Arch

Awolaja Albert

121 Adylin Road
P.O.Box 3828
Harare
Tel: +27631194768
Email: [email protected]

Arch. Awolaja A. B.Es, M.Ed (Lagos)

Brian Muzwembiri
Architect

1 Hwiribidi Street
Msasa Park
Harare
Tel: 814309341
Email: [email protected]

Arch.Muzwembiri B.M BAS, B Arch (NUST)

0773 187 851

Madokero, Harare

41

ARCHITECTS’ YEARBOOK

Bhunu Architecture

140 Nelson Mandela Street
P.O. Box HR 924, Harare
e-mail: [email protected]
cell: 0712 748 817

Arch. Bhunu Shava P MSc Arch (Ukraine)

Bruno Azevedo Private Residence Extension

52 Ridgeway North
P.O. Chisipite
Harare
Tel: 04-884275
Cell: 0772 780 596
email: [email protected]

Arch. Azevedo B.

CGC Wilson

525 Brooke Drive
Borrowdale Brooke
P.O. Box BW 1929
Borrowdale
Harare
Tel: 774238
Email: [email protected]

Arch. Wilson CGC B A (Natal)

42

INSTITUTE OF ARCHITECTS ZIMBABWE

Chikumba Christopher

2/192 Smuts Road
Prospect
Waterfalls
Tel: 0772 855 664
e-mail: [email protected]

Arch Chikumba C. BAS, B Arch NUST

Daniel Mandishona Architect Rainbow Victoria Falls Hotel

7 Mount Road
Avondale
Harare
Tel: 333350/ 336617/ 336618
Cell: 0772 278 243/ 0775 609 525
e-mail: [email protected]

Arch. Mandishona D. BSc Hons, Dip Arch(London)

DesignPro Architect

3505 Takely Drive
Sentosa
Harare
Tel: 0773 226 667/ 0733 390 140
Email: [email protected]/[email protected]

Arch Murwira E. BAS, B Arch (NUST)

Wellpage Business Park, Belgravia, Harare
43

ARCHITECTS’ YEARBOOK

Diagraphis Architects

Suite # 200 Pioneer House
Cnr 8th and Fife
Bulawayo
Tel: 252919
Cell: 0712 200 716 / 0775 842 669
e-mail: [email protected]

Arch. da Cunha Jose Luis Pinto Dip Arch (Brazil)

Fleet Architecture Anchor House
Netone ZITF Pavillion
1 Lewisam Avenue
Chisipite
Harare
Tel: 480346
Cell: 0772 774 029
e-mail: [email protected]w

Arch. Fleet G A. B Arch (Bristol) Dip Arch

G Chitima Architect

Suite 2 Princes Park Mansions
L. Takawira Avenue/S. Parirenyatwa Street
Bulawayo
Tel: 09 887960
Cell: 0772 683 085
e-mail: [email protected]

Arch. Chitima G.

44

We design, manufacture & install customised products as per clienItN’SsTItTaUTsEtOeF A&RCrHeITEqCuTSiZrIeMBmABeWnE ts!

Guaranteed Quality at Best Price and Best Advise! 45

ARCHITECTS’ YEARBOOK

Gil Shepherd Architect

9 David Den Close
Mt Pleasnt Harare
Tel: 336232
Cell: 0772 259 706
e-mail: [email protected]

Arch. Shepherd S. G. B Arch C.T

Village Walk Shopping Centre - in association with Boogertman and Partners (SA)

Gloar Design Team

74 Selous Avenue
Harare
Tel: 0772 309 350
Cell: 0713 386 141
e-mail: [email protected]

Arch. Chikuhuhu O. B Sc Arch, M Sc Arch

Gura and Associate Baines Intercare Hospital
Architect

Stand No 1019 Off Nursery Road
Mt Pleasant
Harare
Tel: 0772 265 543/ 0719 265 543
Email: [email protected]

Arch. I. Gura BAS, B Arch(NUST)

46

INSTITUTE OF ARCHITECTS ZIMBABWE

HBN Simela Architect

6 Barbour Avenue
Parkview
Bulawayo
Tel: 09-88045/72219/77209
Cell: 0737 655 163
e-mail: [email protected]

Arch. Simela G MSc Arch (ODDESA)

Zesa Electricity Industry Pension Fund Parklands Shopping Mall, Bulaway

J. Dzimwasha Architect

4 Meredith Drive
Eastlea
Harare
Tel: 0773 848 676
Email: [email protected]

Arch Dzimwasha J. MSc Arch

CIPF Office Park Ruwa

Juul Trevor

121 Adylin Road
P.O.Box 3828
Harare
Tel: 0782 642 252
Email: [email protected]

Arch. Juul T.D. BA Dip Arch

47

ARCHITECTS’ YEARBOOK CPS Eastlea, Harare

Kurebgaseka Architecture

20 Rhodesville Avenue
Greendale
Tel: 443571/2
Cell: 0712 400 878 /0777 612 834
e-mail: [email protected]

Arch. Kurebgaseka W

M Dip Arch (Cheltenham) Dip Arch (Hull)

Maboreke Architect

No 60 Mt Pleasant Drive
Mt Pleasant
Harare
Tel: 744855/6
Cell: 0772 241 559
e-mail: [email protected]

Arch. Maboreke GM B Arch (Kingstone) Dip Arch

Manditsera T.R. Medical and Dental Practitioners of Zimbabwe Offices

12295 Tynwald South (Westview)
Harare
Tel: 702092
Cell: 0772 690 587
Email: [email protected]

Arch. Manditsera T.R. BAS, BArch (NUST)

48

PLIER INSTITUTE OF ARCHITECTS ZIMBABWE
S
REGI STERED SUP
D
SQ A
Z

AZS APPROVE

Our Promise To You Is Concret4e9

ARCHITECTS’ YEARBOOK IDBZ Offices

Manyara Design

31 Western Road
Greendale
Tel: 486705
Cell: 0772 401 911
e-mail: [email protected]

Arch Manyara O.M. B Sc Arch, M Sc Arch

Mapundu Zvidzai

6 A Athlone Road
Greendale
Harare
Tel: +27 787377794
Email: [email protected]

Arch Mapundu Z. BAS. B Arch (NUST)

Masiyanise T.I Architect

Flat 8 Avon Friars
7 Oxford Road
Avondale
Tel: 339746/334363/5
Cell: 0772 344 907
e-mail: [email protected]

Arch Masiyanise I BA (Hons) Dip Arch (Ports)

50


Click to View FlipBook Version
Previous Book
BUKU SKRAP SEJARAH TAHUN 5
Next Book
LAPORAN VERDIK 21 UITM 2021